Pakistan: Balochistan Road Development Sector Project

Sovereign Project | 34333-013 Status: Closed

Project Results



    kilometers of roads built or upgraded



    average daily vehicle-kilometers using roads built or upgraded in the first full year of operation

The results data reported above are limited to ADB's core sectors, as defined under Strategy 2020 and tracked through indicators in the ADB Results Framework. For definitions of results indicators, please see the ADB Results Framework Indicators Definition.

Project Details

Project Officer
Ning, Jiangbo Central and West Asia Department Request for information
  • Pakistan
  • Loan
  • Transport
Project Name Balochistan Road Development Sector Project
Project Number 34333-013
Country Pakistan
Project Status Closed
Project Type / Modality of Assistance Loan
Source of Funding / Amount
Loan 2019-PAK: Balochistan Road Development Sector Project
Ordinary capital resources US$ 185.70 million
Loan 2020-PAK: Community Development and Poverty Reduction Project (piggy-backed to Balochistan Road Development Sector Project)
concessional ordinary capital resources lending / Asian Development Fund US$ 1.00 million
Strategic Agendas Regional integration
Drivers of Change Governance and capacity development
Knowledge solutions
Sector / Subsector

Transport - Road transport (non-urban)

Gender Equity and Mainstreaming Some gender elements
Project Rationale and Linkage to Country/Regional Strategy

Project Outcome

Description of Outcome
Progress Toward Outcome The overall project progress at the time of loan closing was 77%.
Implementation Progress
Description of Project Outputs
Status of Implementation Progress (Outputs, Activities, and Issues)

Provincial Institutional Development Component

Agree Policy Matrix Implemented: The consultant under this component assisted CWD to meet road sector policy actions agreed between CWD and ADB at project appraisal. Implementation of this component began from 30 June 2005 and completed on 30 June 2009. The following were achieved:

Reorganization of CWD, set up of RMU/RESAC, and development of CWD website.

Supporting RMU/RESAC operations including strengthening of human resources and procurement of equipment.

Establishment of road maintenance and management system together with installation of HDM-4 and development of data base and data collection system.

Capacity building and training of basic technical staff in road design and management, computer aided design, road safety, environment assessment and management, social assessment. The total number of staff trained were: abroad (67) and in-country (421).

Provincial Access Component: Contracts awarded for 15 packages for 440.72 km length of roads, six packages completed (103.72 km) and remaining 9 packages are at various stages of construction. Most of the ongoing subprojects are behind schedule for a number of reasons: (i) security, (ii) price escalation, (iii) land acquisition and resettlement, and (iv) nonperformance of contractors on ICB and LCB contracts

SRPs for 12 LCB packages were approved in April 2010 for implementation and disclosure to affected persons. RESAC has been assigned to undertake internal monitoring and external monitor has recently been appointed to undertake external monitoring. Further revised LARPs for ICB packages 5, 7 and 9 yet to be submitted to ADB for approval.

Cross-border development component comprises physical and nonphysical components: During midterm review mission (13 to 19 Mar. 2008) it was agreed to drop this component from the loan and Government of Pakistan were to finance it from its own resources.

National Highway component: Four contracts of 230.33 km length roads were awarded from Sep. 05 to Apr. 06. The overall physical implementation progress is 70% against the original/revised completion schedule of 97%. The progress of works for the four packages is behind schedule. On NHA's request the reassignment of ICBs 2 and 4 was conditionally approved on 14 April 2009. The reassignment contract was finalized in December 2010.

A 12 months extension in loan closing was approved in March 2010 with quarterly milestones. First quarter milestones were partially achieved. Second quarter milestones were not achieved as noted by PRM-based loan review mission was conducted (19-28 July 2010) and considering (i) unachieved loan extension milestones of the second quarter, (ii) incomplete remaining activities against the assignment of civil works contracts ICBs 2 & 4 since 14 April 2009, (iii) continued deterioration of the law and order, (iv) slow pace of progress, and (v) unimproved implementation trend, concluded that completion of remaining activities within next six months is highly unlikely. In accordance with the already communicated loan extensions (25 March 2010) conditions and unaccomplished milestones of first and second quarters, ADB closed the subject loan on 31 August 2010.

Both NHA and CWD advised to quickly complete all the loan account closing activities enabling ADB to close the loan account on 31 August 2010. Any leftover liabilities after loan account closing would be the responsibility of the Government of Pakistan.

ADB on 8 Sep., 25 Oct., and 3 & 19 Nov. 2010 advised the Borrower, the NHA and CWD that: (i) CWD to refund unutilized IA, reconcile the IA, liquidate against any liabilities by 15 Dec. 2010; (ii) NHA to submit immediately documentation to the assignment of CWs contracts (ICBs 2 & 4); (iii) NHA and CWD to submit all withdrawal applications against all eligible payments for liquidation/reimbursement/direct payment on or before 15 Dec. 2010; and (iv) NHA/CWD to submit Borrower's PCR by 3

Geographical Location

Summary of Environmental and Social Aspects

Environmental Aspects
Involuntary Resettlement
Indigenous Peoples
Stakeholder Communication, Participation, and Consultation
During Project Design
During Project Implementation

Business Opportunities

Consulting Services The Project will require 213 person-months of international and 6,743 person-months of domestic consulting services for (i) institutional development with capacity building under the PIDC, (ii) construction supervision of the civil works for the national highways, and (iii) detailed design and construction supervision for the civil works for the provincial roads. All consultants will be selected in accordance with ADB's Guidelines on the Use of Consultants, and other arrangements satisfactory to ADB for the engagement of domestic consultants. The QCBS procedure will be followed for selection of consulting firms. Both NHA and CWD have agreed to include the relevant sections of ADB's Anticorruption Policy in all invitation bidding documents and contracts.
Procurement Civil works for the national highway component will be procured through four contract packages following international competitive bidding (ICB) among prequalified bidders. ICB will be followed for all civil works contracts with an estimated value exceeding $3.0 million. Civil works contracts with an estimated value equal to or below $3.0 million will follow local competitive bidding procedures acceptable to ADB with separate prequalification. Contracts estimated to cost in excess of $500,000 for goods and related services will be subject to ICB. Civil works for the provincial access component will follow local competitive bidding procedures acceptable to ADB with separate prequalification. Equipment will be procured under international shopping procedures. International shopping procedures will be followed for supply contracts valued at less than $500,000 equivalent and direct purchase procedures will be followed for items valued at less than $100,000. The National Highway Authority (NHA) and the Communication and Works Department (CWD) have agreed to include the relevant sections of ADB's Anticorruption Policy in all bidding documents and contracts.

Responsible Staff

Responsible ADB Officer Ning, Jiangbo
Responsible ADB Department Central and West Asia Department
Responsible ADB Division Pakistan Resident Mission
Executing Agencies
Communication and Works Department, Balochistan
* Mr. Syed Inayatullah Shah
416-D, Samungly Housing Scheme, Quetta
National Highway Authority
* Mr. Mian Muhammad Asghar
House No. 520, Main Margalla Road, F-10/2, Islamabad


Concept Clearance -
Fact Finding -
Approval -
Last Review Mission -
PDS Creation Date 17 Jul 2008
Last PDS Update 25 Feb 2011

Loan 2019-PAK

Approval Signing Date Effectivity Date Closing
Original Revised Actual
20 Nov 2003 17 Mar 2004 20 Aug 2004 31 Dec 2009 31 Dec 2010 08 Apr 2011
Financing Plan Loan Utilization
Total (Amount in US$ million) Date ADB Others Net Percentage
Project Cost 267.30 Cumulative Contract Awards
ADB 185.70 20 Nov 2003 106.92 0.00 94%
Counterpart 81.60 Cumulative Disbursements
Cofinancing 0.00 20 Nov 2003 113.65 0.00 100%

Loan 2020-PAK

Approval Signing Date Effectivity Date Closing
Original Revised Actual
20 Nov 2003 17 Mar 2004 20 Aug 2004 31 Dec 2009 - 30 Jun 2010
Financing Plan Loan Utilization
Total (Amount in US$ million) Date ADB Others Net Percentage
Project Cost 1.25 Cumulative Contract Awards
ADB 1.00 20 Nov 2003 0.43 0.00 98%
Counterpart 0.25 Cumulative Disbursements
Cofinancing 0.00 20 Nov 2003 0.44 0.00 100%

Project Data Sheets (PDS) contain summary information on the project or program. Because the PDS is a work in progress, some information may not be included in its initial version but will be added as it becomes available. Information about proposed projects is tentative and indicative.

The Public Communications Policy (PCP) recognizes that transparency and accountability are essential to development effectiveness. It establishes the disclosure requirements for documents and information ADB produces or requires to be produced.

The Accountability Mechanism provides a forum where people adversely affected by ADB-assisted projects can voice and seek solutions to their problems and report alleged noncompliance of ADB's operational policies and procedures.

In preparing any country program or strategy, financing any project, or by making any designation of, or reference to, a particular territory or geographic area in this document, the Asian Development Bank does not intend to make any judgments as to the legal or other status of any territory or area.

Title Document Type Document Date
Balochistan Road Development Sector Project Project/Program Completion Reports Jun 2012
Balochistan Road Development Sector Project Reports and Recommendations of the President Oct 2003

Safeguard Documents See also: Safeguards

Safeguard documents provided at the time of project/facility approval may also be found in the list of linked documents provided with the Report and Recommendation of the President.

Evaluation Documents See also: Independent Evaluation

None currently available.

Related Publications

None currently available.

The Public Communications Policy (PCP) establishes the disclosure requirements for documents and information ADB produces or requires to be produced in its operations to facilitate stakeholder participation in ADB's decision-making. For more information, refer to the Safeguard Policy Statement, Operations Manual F1, and Operations Manual L3.

Requests for information may also be directed to the InfoUnit.


No tenders for this project were found.

Contracts Awarded

No contracts awarded for this project were found

Procurement Plan

None currently available.